Y--Datil Well CG Double Vault Toilet Socorro (SFO)
INTERIOR, DEPARTMENT OF THE · BUREAU OF LAND MANAGEMENT · NEW MEXICO STATE OFFICE
Small Business Set Aside - TotalNAICS 238910PSC Y1FBAmended
Response deadlineSep 9, 2026
PostedAug 31, 2026
Archive dateSep 24, 2026
Solicitation140L1726Q0048
Notice ID9f80ee931a7c4abdaa5c0383aa426507
Notice typeCombined Synopsis/Solicitation
Set-asideSmall Business Set Aside - Total
Place of performanceNM, 87801
Public-source intelligence
Source-backed opportunity brief
8 citations · 5 sources
Additional information on contractor requirements and worker protections under the EO is available at https://www.dol.gov/agencies/whd/government-contracts.
3729(b)(4). (c) The Contractor must include the substance of this clause, including this paragraph (c), in subcontracts at any tier, including those for commercial products and commercial services, except those where the place of delivery or performance is outside the United States. (End of clause) 52.204-10 Reporting Executive Compensation and First-Tier Subcontract Awards. (JUN 2020) (Deviation Effective Date) 52.204-13 System for Award Management-Maintenance. (OCT 2018) (Deviation Effective Date) 52.204-14 Service Contract Reporting Requirements. (OCT 2016) (Deviation Effective Date) 52.204-19 Incorporation by Reference of Representations and Certifications. (DEC 2014) 52.209-6 Protecting the Government's Interest When Subcontracting With Contractors Debarred, Suspended, Proposed for Debarment, or Voluntarily Excluded. (JAN 2025) (Deviation Effective Date) 52.209-10 Prohibition on Contracting With Inverted Domestic Corporations. (NOV 2015) (Deviation Effective Date) 52.211-12 Liquidated Damages-Construction. (SEP 2000) (a) If the Contractor fails to complete the work within the time specified in the contract, the Contractor shall pay liquidated damages to the Government in the amount of [Contracting Officer insert amount] for each calendar day of delay until the work is completed or accepted. (b) If the Government terminates the Contractor's right to proceed, liquidated damages will continue to accrue until the work is completed.
Each project description must contain the following information: The name of project The project start and end dates A brief description of project and location of the project The owner of project The owners Contact information The total dollar value of the project SUBFACTOR 3 - SCHEDULE The offeror shall provide a detailed work breakdown schedule illustrating the projects critical path including lead times for material ordering and delivery.
The offeror is cautioned that the listed provisions may include blocks that must be completed by the offeror and submitted with its quotation or offer.