This is a solicitation for maintenance dredging of the Mississippi River, specifically from Baton Rouge to the Gulf of Mexico, using a cutterhead dredge. The project magnitude is estimated between $10 million and $25 million, with a response deadline of February 3, 2027. [2]
Key points
Furnish a fully crewed cutterhead dredge for dredging work. [1]
Solicitation will be issued around December 9, 2024. [1]
Offerors must be registered with SAM to receive awards. [1]
Sources
W912P825B0005.pdfHowever, if satisfactory progress has not been made, the Contracting Officer may retain a maximum of 10 percent of the amount of the payment until satisfactory progress is achieved.
Generated from the public notice and source-backed solicitation passages. Confirm important requirements in the cited brief and official documents.
Public-source intelligence
Source-backed opportunity brief
7 citations · 6 sources
These requirements also do not compel Government officials to accept work or services, approve Contractor estimates, perform contract administration functions, or make payment prior to fulfilling their responsibilities. (ii) The prompt payment regulations at 5 CFR 1315.10(c) do not require the Government to pay interest penalties if payment delays are due to disagreement between the Government and the Contractor over the payment amount or other issues involving contract compliance, or on amounts temporarily withheld or retained in accordance with the terms of the contract.
However, no adjustment shall be made under this clause for any suspension, delay, or interruption to the extent that performance would have been so suspended, delayed, or interrupted by any other cause, including the fault or negligence of the Contractor, or for which an equitable adjustment is provided for or excluded under any other term or condition of this contract. (c) A claim under this clause shall not be allowed— (1) For any costs incurred more than 20 days before the Contractor shall have notified the Contracting Officer in writing of the act or failure to act involved (but this requirement shall not apply as to a claim resulting from a suspension order); and (2) Unless the claim, in an amount stated, is asserted in writing as soon as practicable after the termination of the suspension, delay, or interruption, but not later than the date of final payment under the contract. (End of clause) 52.243-4 CHANGES (JUN 2007) (a) The Contracting Officer may, at any time, without notice to the sureties, if any, by written order designated or indicated to be a change order, make changes in the work within the general scope of the contract, including changes-- (1) In the specifications (including drawings and designs); (2) In the method or manner of performance of the work; W912P825B0003 Page 39 of 40 (3) In the Government-furnished property or services; or (4) Directing acceleration in the performance of the work.
52.232-39 Unenforceability of Unauthorized Obligations JUN 2013 52.232-40 Providing Accelerated Payments to Small Business Subcontractors MAR 2023 W912P825B0003 Page 24 of 40 52.233-1 Disputes MAY 2014 52.233-3 Protest After Award AUG 1996 52.233-4 Applicable Law for Breach of Contract Claim OCT 2004 52.236-2 Differing Site Conditions APR 1984 52.236-3 Site Investigation and Conditions Affecting the Work APR 1984 52.236-5 Material and Workmanship APR 1984 52.236-8 Other Contracts APR 1984 52.236-9 Protection of Existing Vegetation, Structures, Equipment, Utilities, and Improvements APR 1984 52.236-10 Operations and Storage Areas APR 1984 52.236-11 Use and Possession Prior to Completion APR 1984 52.236-12 Cleaning Up APR 1984 52.236-14 Availability and Use of Utility Services APR 1984 52.236-21 Specifications and Drawings for Construction FEB 1997 52.236-26 Preconstruction Conference FEB 1995 52.242-5 Payments to Small Business Subcontractors JAN 2017 52.242-15 Stop-Work Order AUG 1989 52.243-7 Notification Of Changes JAN 2017 52.246-12 Inspection of Construction AUG 1996 52.246-21 Warranty of Construction MAR 1994 52.248-3 Value Engineering-Construction OCT 2020 52.249-10 Default (Fixed-Price Construction) APR 1984 52.252-2 Clauses Incorporated By Reference FEB 1998 52.253-1 Computer Generated Forms JAN 1991 252.201-7000 Contracting Officer's Representative DEC 1991 252.203-7000 Requirements Relating to Compensation of Former DoD Officials SEP 2011 252.203-7002 Requirement to Inform Employees of Whistleblower Rights DEC 2022 252.203-7003 Agency Office of the Inspector General AUG 2019 252.204-7003 Control Of Government Personnel Work Product APR 1992 252.204-7012 Safeguarding Covered Defense Information and Cyber Incident Reporting MAY 2024 252.225-7048 Export-Controlled Items JUN 2013 252.232-7003 Electronic Submission of Payment Requests and Receiving Reports DEC 2018 252.232-7010 Levies on Contract Payments DEC 2006 CLAUSES INCORPORATED BY FULL TEXT 52.211-10 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (APR 1984) The Contractor shall be required to (a) commence work under this contract within 15 calendar days after the date the Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than the days described in Section 00010-1.4 of the bidding schedule.
However, if satisfactory progress has not been made, the Contracting Officer may retain a maximum of 10 percent of the amount of the payment until satisfactory progress is achieved.
Extracted from the official notice and archived solicitation files. Confirm controlling requirements in the source documents.
Notice information
Read full notice text
Mississippi River, Baton Rouge to Gulf of Mexico, Southwest Pass Maintenance Dredging, Non-Continuous Mile 6.0 AHP to Mile 19.5 BHP, Cutterhead Dredge No. 3-2025 (OM25277) The work consists of furnishing one fully crewed and equipped cutterhead dredge, with a dredge discharge size of 30 inches or greater inside diameter (ID), complete in all respects, including all attendant plant, and crew. Work will be performed at the Mississippi River Southwest Pass Area and possibly in other areas of the New Orleans District. The magnitude of construction range for this Dredge project is between $10,000,000.00 and $25,000,000.00. This solicitation will be issued on or about 9 December 2024 and a bid opening date will be established in a future amendment. The solicitation documents for this procurement will be posted on Sam.gov. You can access these files from a link located on Sam.gov (www.SAM.gov). You will need the adobe acrobat reader for .pdf files (www.adobe.com) in order to open most files posted by the New Orleans District. You are encouraged, for marketing purposes, to register as an Interested Vendor in beta.Sam.gov (www.beta.SAM.gov). This can be done by clicking on the solicitation title and clicking on the button that says Register as an Interested Vendor and entering your business information. Offerers are also encouraged to post notices of prospective subcontracting opportunities on the Small Business Administration's Subnet, at http://web.sba.gov/subnet. Offerers must be registered with the System for Award Management (SAM), in order to receive a Government contract award. To register, the SAM Internet address is: http://www.sam.gov. The Contract Specialists for this solicitation is Cori A.Caimi at 504-862-1352 (email Cori.A.Caimi@usace.army.mil) or Bambi Raja at 504-862-1499 (email Bambi.l.raja@usace.army.mil). Amendment 0001: 1. Make changes to the Solicitation; Update instructions for inquiries regarding this Solicitation Note: Amendment 0001 does not set a bid opening date. Should a bid opening be needed, another amendment request will be submitted.
What changed
Apr 27, 2026 · 2 fields changed
DescriptionMississippi River, Baton Rouge to Gulf of Mexico, Southwest Pass Maintenance Dredging, Non-Continuous Mile 6.0 AHP to Mile 19.5 BHP, Cutterhead Dredge No. 3-2025 (OM25277) The work consists of furnishing one fully crewed and equipped cutterhead dredge, with a dredge discharge size of 30 inches or greater inside diameter (ID), complete in all respects, including all attendant plant, and crew. Work will be performed at the Mississippi River Southwest Pass Area and possibly in other areas of the New Orleans District. The magnitude of construction range for this Dredge project is between $10,000,000.00 and $25,000,000.00. This solicitation will be issued on or about 9 December 2024 and a bid opening date will be established in a future amendment. The solicitation documents for this procurement will be posted on Sam.gov. You can access these files from a link located on Sam.gov (www.SAM.gov). You will need the adobe acrobat reader for .pdf files (www.adobe.com) in order to open most files posted by the New Orleans District. You are encouraged, for marketing purposes, to register as an Interested Vendor in beta.Sam.gov (www.beta.SAM.gov). This can be done by clicking on the solicitation title and clicking on the button that says Register as an Interested Vendor and entering your business information. Offerers are also encouraged to post notices of prospective subcontracting opportunities on the Small Business Administration's Subnet, at http://web.sba.gov/subnet. Offerers must be registered with the System for Award Management (SAM), in order to receive a Government contract award. To register, the SAM Internet address is: http://www.sam.gov. The Contract Specialists for this solicitation is Cori A.Caimi at 504-862-1352 (email Cori.A.Caimi@usace.army.mil) or Bambi Raja at 504-862-1499 (email Bambi.l.raja@usace.army.mil).Mississippi River, Baton Rouge to Gulf of Mexico, Southwest Pass Maintenance Dredging, Non-Continuous Mile 6.0 AHP to Mile 19.5 BHP, Cutterhead Dredge No. 3-2025 (OM25277) The work consists of furnishing one fully crewed and equipped cutterhead dredge, with a dredge discharge size of 30 inches or greater inside diameter (ID), complete in all respects, including all attendant plant, and crew. Work will be performed at the Mississippi River Southwest Pass Area and possibly in other areas of the New Orleans District. The magnitude of construction range for this Dredge project is between $10,000,000.00 and $25,000,000.00. This solicitation will be issued on or about 9 December 2024 and a bid opening date will be established in a future amendment. The solicitation documents for this procurement will be posted on Sam.gov. You can access these files from a link located on Sam.gov (www.SAM.gov). You will need the adobe acrobat reader for .pdf files (www.adobe.com) in order to open most files posted by the New Orleans District. You are encouraged, for marketing purposes, to register as an Interested Vendor in beta.Sam.gov (www.beta.SAM.gov). This can be done by clicking on the solicitation title and clicking on the button that says Register as an Interested Vendor and entering your business information. Offerers are also encouraged to post notices of prospective subcontracting opportunities on the Small Business Administration's Subnet, at http://web.sba.gov/subnet. Offerers must be registered with the System for Award Management (SAM), in order to receive a Government contract award. To register, the SAM Internet address is: http://www.sam.gov. The Contract Specialists for this solicitation is Cori A.Caimi at 504-862-1352 (email Cori.A.Caimi@usace.army.mil) or Bambi Raja at 504-862-1499 (email Bambi.l.raja@usace.army.mil). Amendment 0001: 1. Make changes to the Solicitation; Update instructions for inquiries regarding this Solicitation Note: Amendment 0001 does not set a bid opening date. Should a bid opening be needed, another amendment request will be submitted.Documents12