The Department of Defense seeks a cutterhead dredge for maintenance dredging in the Mississippi River Southwest Pass Area, with a construction range of $10M to $25M. The work requires furnishing a fully crewed and equipped cutterhead dredge with a 30-inch ID discharge. [1]
Key points
Dredge must have a 30-inch or greater inside diameter discharge. [1]
Contractor entries include daily reports, submittals, and payment requests. [2]
W912P825B0006.pdf252.203-7002 252.203-7003 252.204-7003 252.204-7012 252.225-7048 252.232-7003 252.232-7010 MAY 2014 AUG 1996 OCT 2004 APR 1984 APR 1984 APR 1984 APR 1984 APR 1984 Disputes Protest After Award Applicable Law for Breach of Contract Claim Differing Site Conditions Site Investigation and Conditions Affecting the Work Material and Workmanship Other Contracts Protection of Existing Vegetation, Structures, Equipment, Utilities, and Improvements Operations and Storage Areas Use and Possession Prior to Completion Cleaning Up Availability and Use of Utility Services Specifications and Drawings for Construction Preconstruction Conference Payments to Small Business Subcontractors Stop-Work Order Notific
W912P825B0006.pdfContractor entries generally include prime and subcontractor information, daily reports, submittals, RFI's, schedule updates, and payment requests.
Generated from the public notice and source-backed solicitation passages. Confirm important requirements in the cited brief and official documents.
Public-source intelligence
Source-backed opportunity brief
7 citations · 6 sources
252.203-7002 252.203-7003 252.204-7003 252.204-7012 252.225-7048 252.232-7003 252.232-7010 MAY 2014 AUG 1996 OCT 2004 APR 1984 APR 1984 APR 1984 APR 1984 APR 1984 Disputes Protest After Award Applicable Law for Breach of Contract Claim Differing Site Conditions Site Investigation and Conditions Affecting the Work Material and Workmanship Other Contracts Protection of Existing Vegetation, Structures, Equipment, Utilities, and Improvements Operations and Storage Areas Use and Possession Prior to Completion Cleaning Up Availability and Use of Utility Services Specifications and Drawings for Construction Preconstruction Conference Payments to Small Business Subcontractors Stop-Work Order Notification Of Changes Inspection of Construction Warranty of Construction Value Engineering-Construction Default (Fixed-Price Construction) Clauses Incorporated By Reference Computer Generated Forms Contracting Officer's Representative Requirements Relating to Compensation of Former DoD Officials Requirement to Inform Employees of Whistleblower Rights DEC 2022 AUG 2019 Agency Office of the Inspector General APR 1992 Control Of Government Personnel Work Product MAY 2024 Safeguarding Covered Defense Information and Cyber Incident Reporting Export-Controlled Items Electronic Submission of Payment Requests and Receiving Reports Levies on Contract Payments APR 1984 APR 1984 APR 1984 APR 1984 FEB 1997 FEB 1995 JAN 2017 AUG 1989 JAN 2017 AUG 1996 MAR 1994 OCT 2020 APR 1984 FEB 1998 JAN 1991 DEC 1991 SEP 2011 JUN 2013 DEC 2018 DEC 2006 CLAUSES INCORPORATED BY FULL TEXT 52.211-10 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (APR 1984) The Contractor shall be required to (a) commence work under this contract within 15 calendar days after the date the Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than the days described in Section 00010-1.4 of the bidding schedule.
However, no adjustment shall be made under this clause for any suspension, delay, or interruption to the extent that performance would have been so suspended, delayed, or interrupted by any other cause, including the fault or negligence of the Contractor, or for which an equitable adjustment is provided for or excluded under any other term or condition of this contract. (c) A claim under this clause shall not be allowed— (1) For any costs incurred more than 20 days before the Contractor shall have notified the Contracting Officer in writing of the act or failure to act involved (but this requirement shall not apply as to a claim resulting from a suspension order); and (2) Unless the claim, in an amount stated, is asserted in writing as soon as practicable after the termination of the suspension, delay, or interruption, but not later than the date of final payment under the contract. (End of clause) 52.243-4 CHANGES (JUN 2007) (a) The Contracting Officer may, at any time, without notice to the sureties, if any, by written order designated or indicated to be a change order, make changes in the work within the general scope of the contract, including changes-- (1) In the specifications (including drawings and designs); (2) In the method or manner of performance of the work; W912P825B0003 Page 39 of 40 (3) In the Government-furnished property or services; or (4) Directing acceleration in the performance of the work.
Extracted from the official notice and archived solicitation files. Confirm controlling requirements in the source documents.
Notice information
Read full notice text
Mississippi River, Baton Rouge to Gulf of Mexico, Southwest Pass Maintenance Dredging, Non-Continuous Mile 6.0 AHP to Mile 19.5 BHP, Cutterhead Dredge No. 4-2025 (OM25278) The work consists of furnishing one fully crewed and equipped cutterhead dredge, with a dredge discharge size of 30 inches or greater inside diameter (ID), complete in all respects, including all attendant plant, and crew. Work will be performed at the Mississippi River Southwest Pass Area and possibly in other areas of the New Orleans District. The magnitude of construction range for this Dredge project is between $10,000,000.00 and $25,000,000.00. This solicitation will be issued on or about 9 December 2024 and a bid opening date will be established in a future amendment. The solicitation documents for this procurement will be posted on Sam.gov. You can access these files from a link located on Sam.gov (www.SAM.gov). You will need the adobe acrobat reader for .pdf files (www.adobe.com) in order to open most files posted by the New Orleans District. You are encouraged, for marketing purposes, to register as an Interested Vendor in beta.Sam.gov (www.beta.SAM.gov). This can be done by clicking on the solicitation title and clicking on the button that says Register as an Interested Vendor and entering your business information. Offerers are also encouraged to post notices of prospective subcontracting opportunities on the Small Business Administration's Subnet, at http://web.sba.gov/subnet. Offerers must be registered with the System for Award Management (SAM), in order to receive a Government contract award. To register, the SAM Internet address is: http://www.sam.gov. The Contract Specialists for this solicitation is Cori A.Caimi at 504-862-1352 (email Cori.A.Caimi@usace.army.mil) or Bambi Raja at 504-862-1499 (email Bambi.l.raja@usace.army.mil).