F FedRoster
Create account
Menu
← Active opportunities
OpenSolicitationAmended

Mississippi River, Baton Rouge to Gulf of Mexico, Southwest Pass Hopper Dredge Contract Nos. 2-2025 (OM25002)

Solicitation numberW912P825B0009

DEPT OF DEFENSE · DEPT OF THE ARMY · W07V ENDIST NEW ORLEANS

NAICS 237990 · Other Heavy and Civil Engineering ConstructionPSC Y1KF · Construction Of Dredging Facilities
View opportunity on SAM.gov ↗
Response deadlineMar 23, 2027, 3:30 PM UTC
Deadline status201 days remaining
PostedMar 25, 2025
Record refreshedSep 2, 2026
Place of performancePlaquemine, LA, United States

Opportunity summary

Source-cited

This solicitation is for a Hopper Dredge Contract to operate in the Mississippi River, from Baton Rouge to the Gulf of Mexico, with a construction range of $10M to $25M. The work requires furnishing one fully crewed and equipped self-propelled trailing suction type hopper dredge. [1][2]

Key points

  • Work involves furnishing a fully crewed, self-propelled hopper dredge. [1]
  • Performance location is Plaquemine, LA, USA. [2]

Watch items

  • Response deadline is March 23, 2027. [2]
  • Contractors must be registered with SAM. [1]

Sources

  1. W912P825B0009.pdf52.236-8 Other Contracts APR 1984 52.236-9 Protection of Existing Vegetation, Structures, Equipment, Utilities, and Improvements APR 1984 52.236-10 Operations and Storage Areas APR 1984 52.236-11 Use and Possession Prior to Completion APR 1984 52.236-12 Cleaning Up APR 1984 52.236-14 Availability and Use of Utility Services APR 1984 52.236-21 Specifications and Drawings for Construction FEB 1997 52.236-26 Preconstruction Conference FEB 1995 52.242-5 Payments to Small Business Subcontractors JAN 2017 52.242-15 Stop-Work Order AUG 1989 52.243-7 Notification Of Changes JAN 2017 52.246-12 Inspection of Construction AUG 1996 52.246-21 Warranty of Construction MAR 1994 52.248-3 Value Engineering-C
  2. Official SAM.gov noticePlace of performance: Plaquemine, LA, USA

Generated from the public notice and source-backed solicitation passages. Confirm important requirements in the cited brief and official documents.

Public-source intelligence

Source-backed opportunity brief

7 citations · 6 sources

52.236-8 Other Contracts APR 1984 52.236-9 Protection of Existing Vegetation, Structures, Equipment, Utilities, and Improvements APR 1984 52.236-10 Operations and Storage Areas APR 1984 52.236-11 Use and Possession Prior to Completion APR 1984 52.236-12 Cleaning Up APR 1984 52.236-14 Availability and Use of Utility Services APR 1984 52.236-21 Specifications and Drawings for Construction FEB 1997 52.236-26 Preconstruction Conference FEB 1995 52.242-5 Payments to Small Business Subcontractors JAN 2017 52.242-15 Stop-Work Order AUG 1989 52.243-7 Notification Of Changes JAN 2017 52.246-12 Inspection of Construction AUG 1996 52.246-21 Warranty of Construction MAR 1994 52.248-3 Value Engineering-Construction OCT 2020 52.249-10 Default (Fixed-Price Construction) APR 1984 52.253-1 Computer Generated Forms JAN 1991 252.201-7000 Contracting Officer's Representative DEC 1991 252.203-7000 Requirements Relating to Compensation of Former DoD Officials SEP 2011 252.203-7002 Requirement to Inform Employees of Whistleblower Rights DEC 2022 252.203-7003 Agency Office of the Inspector General AUG 2019 252.204-7003 Control Of Government Personnel Work Product APR 1992 252.204-7012 Safeguarding Covered Defense Information and Cyber Incident Reporting MAY 2024 252.225-7048 Export-Controlled Items JUN 2013 252.232-7003 Electronic Submission of Payment Requests and Receiving Reports DEC 2018 252.232-7010 Levies on Contract Payments DEC 2006 CLAUSES INCORPORATED BY FULL TEXT 52.211-10 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (APR 1984) The Contractor shall be required to (a) commence work under this contract within 5 calendar days after the date the Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than the days described in Section 00010 paragraph entitled "Conditions of Contract Award.” The time stated for completion shall include final cleanup of the premises. (End of clause) Note: The term "commence work" in this clause refers to commence dredging.

[1] W912P825B0009.pdf

Scope

However, no adjustment shall be made under this clause for any suspension, delay, or interruption to the extent that performance would have been so suspended, delayed, or interrupted by any other cause, including the fault or negligence of the Contractor, or for which an equitable adjustment is provided for or excluded under any other term or condition of this contract. (c) A claim under this clause shall not be allowed— (1) For any costs incurred more than 20 days before the Contractor shall have notified the Contracting Officer in writing of the act or failure to act involved (but this requirement shall not apply as to a claim resulting from a suspension order); and (2) Unless the claim, in an amount stated, is asserted in writing as soon as practicable after the termination of the suspension, delay, or interruption, but not later than the date of final payment under the contract. (End of clause) 52.243-4 CHANGES (JUN 2007) (a) The Contracting Officer may, at any time, without notice to the sureties, if any, by written order designated or indicated to be a change order, make changes in the work within the general scope of the contract, including changes-- (1) In the specifications (including drawings and designs); (2) In the method or manner of performance of the work; (3) In the Government-furnished property or services; or (4) Directing acceleration in the performance of the work. (b) Any other written or oral order (which, as used in this paragraph (b), includes direction, instruction, interpretation, or determination) from the Contracting Officer that causes a change shall be treated as a change order under this clause; provided, that the Contractor gives the Contracting Officer written notice stating (1) the date, circumstances, and source of the order and (2) that the Contractor regards the order as a change order. (c) Except as provided in this clause, no order, statement, or conduct of the Contracting Officer shall be treated as a change under this clause or entitle the Contractor to an equitable adjustment.

[1] W912P825B0009.pdf

Deliverables

Contractor entries generally include prime and subcontractor information, daily reports, submittals, RFI's, schedule updates, and payment requests.

[1] W912P825B0009.pdf

Submission

The offeror is cautioned that the listed provisions may include blocks that must be completed by the offeror and submitted with its quotation or offer.

[1] W912P825B0009.pdf

Extracted from the official notice and archived solicitation files. Confirm controlling requirements in the source documents.

Notice information

Read full notice text

Mississippi River, Baton Rouge to Gulf of Mexico, Southwest Pass Hopper Dredge Contract No. 2-2025 (OM25002) The work consists of furnishing one fully crewed and equipped self-propelled trailing suction type hopper dredge. Work will be performed in Mississippi River Southwest Pass and possibly in other areas of the New Orleans District, in areas of both the Galveston and Mobile Districts, and in other areas deemed necessary. The magnitude of construction range for this Dredge project is between $10,000,000.00 and $25,000,000.00. A bid opening date will be established in a future amendment. You can access these files from a link located on Sam.gov (www.SAM.gov). You will need the adobe acrobat reader for .pdf files (www.adobe.com) in order to open most files posted by the New Orleans District. You are encouraged, for marketing purposes, to register as an Interested Vendor in beta.Sam.gov (www.beta.SAM.gov). This can be done by clicking on the solicitation title and clicking on the button that says Register as an Interested Vendor and entering your business information. Offerers are also encouraged to post notices of prospective subcontracting opportunities on the Small Business Administration's Subnet, at http://web.sba.gov/subnet. Offerers must be registered with the System for Award Management (SAM), in order to receive a Government contract award. To register, the SAM Internet address is: http://www.sam.gov. The Contract Specialists for this solicitation is Cori A.Caimi at 504-862-1352 (email Cori.A.Caimi@usace.army.mil) or Bambi Raja at 504-862-1499 (email Bambi.l.raja@usace.army.mil).

What changed

Mar 25, 2025 · 5 fields changed
Notice typePresolicitationSolicitation
Response deadline2027-02-28T17:00:00+00:002027-03-23T15:30:00+00:00
Archive date2027-03-152027-04-07
DescriptionMississippi River, Baton Rouge to Gulf of Mexico, Southwest Pass Hopper Dredge Contract Nos. 2-2025 (OM25002) The work consists of furnishing one fully crewed and equipped self-propelled trailing suction type hopper dredge. Work will be performed in Mississippi River Southwest Pass and possibly in other areas of the New Orleans District, in areas of both the Galveston and Mobile Districts, and in other areas deemed necessary. The magnitude of construction range for this Dredge project is between $10,000,000.00 and $25,000,000.00. This solicitation will be issued on or about 9 December 2024 and a bid opening date will be established in a future amendment. The solicitation documents for this procurement will be posted on Sam.gov. You can access these files from a link located on Sam.gov (www.SAM.gov). You will need the adobe acrobat reader for .pdf files (www.adobe.com) in order to open most files posted by the New Orleans District. You are encouraged, for marketing purposes, to register as an Interested Vendor in beta.Sam.gov (www.beta.SAM.gov). This can be done by clicking on the solicitation title and clicking on the button that says Register as an Interested Vendor and entering your business information. Offerers are also encouraged to post notices of prospective subcontracting opportunities on the Small Business Administration's Subnet, at http://web.sba.gov/subnet. Offerers must be registered with the System for Award Management (SAM), in order to receive a Government contract award. To register, the SAM Internet address is: http://www.sam.gov. The Contract Specialists for this solicitation is Cori A.Caimi at 504-862-1352 (email Cori.A.Caimi@usace.army.mil) or Bambi Raja at 504-862-1499 (email Bambi.l.raja@usace.army.mil).Mississippi River, Baton Rouge to Gulf of Mexico, Southwest Pass Hopper Dredge Contract No. 2-2025 (OM25002) The work consists of furnishing one fully crewed and equipped self-propelled trailing suction type hopper dredge. Work will be performed in Mississippi River Southwest Pass and possibly in other areas of the New Orleans District, in areas of both the Galveston and Mobile Districts, and in other areas deemed necessary. The magnitude of construction range for this Dredge project is between $10,000,000.00 and $25,000,000.00. A bid opening date will be established in a future amendment. You can access these files from a link located on Sam.gov (www.SAM.gov). You will need the adobe acrobat reader for .pdf files (www.adobe.com) in order to open most files posted by the New Orleans District. You are encouraged, for marketing purposes, to register as an Interested Vendor in beta.Sam.gov (www.beta.SAM.gov). This can be done by clicking on the solicitation title and clicking on the button that says Register as an Interested Vendor and entering your business information. Offerers are also encouraged to post notices of prospective subcontracting opportunities on the Small Business Administration's Subnet, at http://web.sba.gov/subnet. Offerers must be registered with the System for Award Management (SAM), in order to receive a Government contract award. To register, the SAM Internet address is: http://www.sam.gov. The Contract Specialists for this solicitation is Cori A.Caimi at 504-862-1352 (email Cori.A.Caimi@usace.army.mil) or Bambi Raja at 504-862-1499 (email Bambi.l.raja@usace.army.mil).
DocumentsNot previously reported1

Notice history

Attachments

Open a filename to view the saved source file. If a saved copy is not available yet, FedRoster will continue to the matching SAM.gov notice.

Back to top ↑